Section 1 — Who We Are
Right Deal Roofing & Chimney, LLC is a licensed roofing and chimney contractor operating in the Commonwealth of Pennsylvania, primarily serving residential property owners in Bucks County and Montgomery County.
Section 2 — Acceptance of Terms
By accessing or using rightdealconstruction.com (the "Website"), you agree to be legally bound by these Terms & Conditions. If you do not agree to these terms, you must discontinue use of the Website immediately. These Terms apply to all visitors, users, and anyone who accesses the Website — including those who submit estimate requests, view project photos, or read content.
Section 3 — Intellectual Property
All content on this Website — including text, design layouts, graphics, source code, logos, and photography — is the exclusive property of Right Deal Roofing & Chimney, LLC and is protected under applicable United States intellectual property laws.
Before and After Photography
All before-and-after project photography displayed on this Website is owned by Right Deal Construction, LLC. This photography was taken by or on behalf of Right Deal Roofing & Chimney during active project engagements. It is not licensed to third parties and may not be reproduced, distributed, or used in any commercial or non-commercial context without explicit written consent from Right Deal Roofing & Chimney, LLC.
Customer Testimonials
Testimonials and customer reviews displayed on this Website are used with the knowledge of the reviewer. Right Deal Roofing & Chimney retains the right to use such testimonials for marketing and credibility purposes across all platforms and channels.
Prohibited Uses
You may not copy, reproduce, distribute, transmit, publish, license, create derivative works from, or sell any content from this Website without prior written authorization from Right Deal Roofing & Chimney, LLC.
Section 4 — Website Accuracy Disclaimer
The content on this Website is provided for general informational purposes only. While we make every effort to ensure accuracy, Right Deal Roofing & Chimney does not warrant that pricing information, service availability, project timelines, or scope descriptions are complete, current, or free of errors. All pricing, availability, and scope of work are subject to change and are finalized only after an in-person on-site assessment by a Right Deal Construction representative.
Section 5 — Online and Phone Estimates Are Not Binding Contracts
Any estimate provided through this Website's contact form, by telephone, or by email is a good-faith, preliminary pricing range based solely on the information provided at the time of request. It is not a binding contract, a fixed price, or a guarantee of service availability.
What an Estimate Is
An estimate from Right Deal Roofing & Chimney is an approximation of cost and scope, intended to give you a reasonable starting point for budgeting your project. It is prepared in good faith using the information you have provided and our general knowledge of roofing and chimney projects in the Bucks and Montgomery County area.
What Triggers a Binding Contract
A legally binding agreement between you and Right Deal Roofing & Chimney is created only when both parties have signed a written project proposal. That signed proposal will specify the exact scope of work, materials, price, timeline, and payment terms. Until that document is signed by both parties, no contractual obligation exists.
Variance from Estimates
Final project pricing may vary from an initial estimate based on conditions discovered during the on-site inspection — including, but not limited to, hidden structural damage, code compliance requirements, material availability changes, or scope adjustments requested by the homeowner. Any material change to scope or price will be communicated in writing before work proceeds.
Section 6 — Pennsylvania Mechanics' Lien Notice
Under Pennsylvania law (the Mechanics' Lien Law, 49 P.S. § 1101 et seq.), contractors, subcontractors, and material suppliers who furnish labor, materials, or services for the improvement of real property have the right to file a mechanics' lien against that property if they are not paid for their work.
This notice is provided for informational purposes and is standard practice for licensed contractors operating in Pennsylvania. It does not reflect adversarial intent — it reflects our professional transparency regarding both your rights and ours under Pennsylvania law. In the event of a payment dispute, Right Deal Roofing & Chimney is committed to resolving it directly with you before pursuing any legal remedy.
Section 7 — Permits, Codes, and Compliance
Right Deal Roofing & Chimney performs all work in compliance with applicable Pennsylvania building codes and local municipal requirements in Bucks County and Montgomery County, Pennsylvania.
Permit Responsibility
For projects requiring building permits — which may include structural roofing replacements, chimney rebuilds, and certain repairs depending on local municipal requirements — the party responsible for obtaining the permit will be clearly identified in the signed project contract. Right Deal Roofing & Chimney can pull required permits on your behalf where we are authorized to do so. Failure to obtain required permits is the responsibility of the party designated in the signed contract.
Section 8 — Warranty Scope Disclaimer
Two distinct types of warranties may apply to your project, and it is important to understand the difference between them:
Manufacturer Material Warranties
Materials installed by Right Deal Roofing & Chimney — including roofing shingles (e.g., GAF, Owens Corning), underlayment, flashing, and chimney components — may carry manufacturer warranties. These warranties are issued directly by the manufacturer, governed entirely by the manufacturer's terms and conditions, and are not administered by Right Deal Construction. You will receive applicable manufacturer warranty documentation at project completion.
Right Deal Roofing & Chimney Labor Warranty
Right Deal Roofing & Chimney provides a workmanship warranty on our installation labor. The specific duration, scope, and terms of this warranty are stated in your signed project contract. The labor warranty covers defects in installation that arise from our workmanship and does not cover damage caused by weather events, third-party modifications, normal wear and tear, or conditions pre-existing the project.
Section 9 — Force Majeure & Schedule Delays
Project timelines are estimates and are subject to change due to circumstances beyond Right Deal Roofing & Chimney's reasonable control, including but not limited to:
- Inclement weather, severe weather events, or unsafe working conditions
- Material supply chain delays, manufacturer back-orders, or shipping disruptions
- Permit processing delays at the relevant municipal authority
- Labor unavailability due to illness, injury, or emergency
- Government actions, public health emergencies, or acts of God
In the event of a schedule delay caused by any of the above, Right Deal Roofing & Chimney will notify you as promptly as practicable and work to reschedule at the earliest available opportunity. A delay caused by force majeure circumstances does not constitute a breach of contract by Right Deal Roofing & Chimney.
Section 10 — Limitation of Liability
To the maximum extent permitted by applicable Pennsylvania law, Right Deal Roofing & Chimney's total liability arising from or related to any specific project engagement shall not exceed the total value of the signed contract for that specific project.
Right Deal Roofing & Chimney shall not be liable for any indirect, incidental, consequential, special, or punitive damages arising from the use of this Website or from any service engagement — including loss of use, loss of revenue, or costs of substitute services — even if Right Deal Roofing & Chimney has been advised of the possibility of such damages.
Section 11 — Governing Law & Dispute Venue
These Terms & Conditions are governed by and construed in accordance with the laws of the Commonwealth of Pennsylvania, without regard to its conflict of law provisions.
Any legal dispute, claim, or action arising from or relating to these Terms or any service engagement with Right Deal Roofing & Chimney shall be subject to the exclusive jurisdiction and venue of the Court of Common Pleas of Bucks County, Pennsylvania. By using this Website or engaging Right Deal Roofing & Chimney for services, you consent to the personal jurisdiction of such courts.
Right Deal Roofing & Chimney reserves the right to update or amend these Terms & Conditions at any time. The "Last Updated" date at the top of this page reflects the most recent revision. Continued use of this Website after any update constitutes your acceptance of the revised Terms.
Frequently Asked Questions
These questions represent the most common legal and service inquiries we receive from homeowners in Bucks and Montgomery Counties before committing to a project.
Is a Right Deal Roofing & Chimney estimate a binding contract?
No. Any estimate provided online, by phone, or by email is a good-faith, preliminary pricing range based on the information available at the time of request. A legally binding contract is created only when both parties have signed a written project proposal. Final pricing may vary from the estimate based on scope or conditions discovered during the on-site inspection.
What law governs a dispute with Right Deal Roofing & Chimney?
All disputes arising from our website or our services are governed by the laws of the Commonwealth of Pennsylvania. The venue for any legal proceedings is the Court of Common Pleas of Bucks County, Pennsylvania.
Who owns the before and after photos from my project?
All before-and-after photography taken by or on behalf of Right Deal Roofing & Chimney during a project is owned by Right Deal Roofing & Chimney, LLC, and may be used for marketing, portfolio, and business development purposes. If you have questions about photos from a specific project, please contact us directly.
What warranties does Right Deal Roofing & Chimney provide?
Two types of warranties apply: (1) Manufacturer material warranties — e.g., GAF, Owens Corning — issued by the manufacturer and governed entirely by their terms; and (2) Right Deal Roofing & Chimney labor warranty covering installation workmanship, with full terms specified in your signed project contract.
Which Pennsylvania counties does Right Deal Roofing & Chimney serve?
Right Deal Roofing & Chimney serves homeowners throughout Bucks County and Montgomery County, Pennsylvania — including Doylestown, Lansdale, Blue Bell, Horsham, Warminster, Warrington, Newtown, and surrounding communities.